Subcontractor Was Wrongfully Terminated Where Its Performance was Delayed by the Prime Contractor and Others
ConstructionRisk.com Report Vol. #13, Issue #7
See article in the following topic indices:
Damages - Liquidated,Default Termination,Delay,Interference with Contract,Liquidated damages,Termination
Email this page to a friend:
Demolition delays by others for whom the subcontractor was not responsible significantly impeded the subcontractor’s ability to timely perform its work. Stored equipment and activity of other subcontractors prevented the subcontractor from accessing work areas. And revisions to plans that were required as a result of design errors required removal and relocation of piping the [...]
Email this page to a friend:
Liquidated damage assessment against contractor
Damages - Liquidated,Federal Government Contracts,Liquidated damages,Punitive Damages
Email this page to a friend:
When the amount of damages is difficult to predict, a liquidated damages clause will generally be upheld unless the court determines that the clause was intended to be a penalty rather than liquidated damages. In Safeco Credit v. U.S., 44 Fed.Cl. 406 (1999), a contractor was assessed damages by the Department of Navy for late [...]
Email this page to a friend:
